An Analysis Of Jane Austen s Jane Eyre - 1049 Words

When Jane left me, to retire, I longed for sleep to overcome me. But it would not. Oh, how I hate when one can not enter into a deep sleep, that is when the deepest, darkest thoughts come to mind. When one has the time to ponder life’s mysteries, to reflect on life’s hardships and when one has the time to reflect on what one should and should not have said. It was long after Jane left me, when my deepest fears, darkest memories and worst secrets came to mind. What if Jane found out? Jane, Jane, lovelies Jane. So pure, so innocent. She can never find out about my secret. No one can ever find out. My secret has haunted me for 15 long years, and for 15 long years my secret has remained hidden from the world. But, is it possible, that Jane†¦show more content†¦Then all I had to do was wait for my beautiful bride. At six-fifteen I wanted John to start loading the cart, for soon after our marriage, Jane and I, newlywed, would be on our way to all the places Jane desi red to go. â€Å"Ms. Jane Eyre is awake and is preparing, sir.† My new foot man informed me. â€Å"Thank you.† He left. I sat around a half hour more before beginning to grow impatient. I called out â€Å"Jane† just as I hit the foot of the stairs, thinking that if my dear Jane would not come down soon I shall have to go and retrieve her myself. But, I need not, for as I was about to hasten up the stairs, my beautiful Jane stepped out of her room and descended the stairs. â€Å"Linger,† said I, â€Å"My brain is on fire with impatience, and you tarry so long!† Taking her into the dining room I surveyed her and pronounced her fair as a lily, and not only the pride of my life, but the desire of my eyes. Informing Jane thet I would give her just ten minutes to eat, I rang the bell and a footman appered. â€Å"Is John getting the carriage ready?† â€Å"Yes sir.† was hir reply. â€Å"Is the luggage brought down?† â€Å"They are bringing it down now sir.† â€Å"Go to the church: see if Mr. Wood and the clerk are there: run and tell me.† With those instructions the footman left. Oh, how impatience ran through me. How I wished to be married, before my secret was found out by Jane, and before Mr.

Scarlet Letter Literary Criticism Essay - 883 Words

Scarlet Letter Literary Criticism nbsp;nbsp;nbsp;nbsp;nbsp;All great stories have thorough reports from several different literary critics, what do they have to say on The Scarlet Letter? The Scarlet Letter in the nineteenth century is comparable to early twentieth century and late twentieth century criticism. nbsp;nbsp;nbsp;nbsp;nbsp;Early nineteenth century critics think the story was a tremendous work of art. A â€Å"Review of New Books† thought the story is â€Å"a genuine native romance† (Ripley 295). This is shown through the struggle of Hester and Arthur to have a secret love affair and find time to see each other periodically throughout the story. Ripley believes The Scarlet Letter is his greatest work by â€Å"imposing splendor of†¦show more content†¦This was very interesting, because it is a different twist to the normal happy story. The people in the story as a whole are spoken of. The people in the story were more symbolic than just a character, â€Å"very picturesquely arranged,† mainly because the story isn’t about them, but what they stand for (James 29). For instance, Pearl is the living sin. Nineteenth century criticism is positive to the story. nbsp;nbsp;nbsp;nbsp;nbsp;Early twentieth century criticism continues what took place in nineteenth century criticism, to be very optimistic about the story, but takes a deeper look into the main characters. Mark Van Doven points out the greatness of the characters. He explains Pearl in a short, but fascinating way, â€Å"Pearl has something supernatural about her. She may even be the devil’s child (Van Doren 135). Pearl, the living sin, haunts Hester at times with her tricky questions. Van Doren says of Dimmesdale, â€Å"Dimmesdale’s purpose, still do not give him peace. The blood comes, but not his soul, for there is no penitence. He tortures, but cannot purify himself† (131). He is a sad character in this story. It seems like all he does is suffer and suffer. Either way, Arthur would have been tortured, either physically or mentally. If he came out early on, they would have killed him, but he kept it in, so he suffered mentally. Hawthorne did this magically. V an Doven speaks highest on Hawthorne’s work of Hester, â€Å"Hester becomes a heroine, almost a goddess, into when theShow MoreRelatedThe Scarlet Letter By Nathaniel Hawthorne1397 Words   |  6 Pages John Graves Professor Connie Caskey English 251: American Literature I 8 February 2016 The Scarlet Letter was written by Nathaniel Hawthorne in 1850 which is based on the time frame of the Puritans, a religious group who arrived in Massachusetts in the 1630’s. The Puritans were in a religious period that was known for the strict social norms in which lead to the intolerance of different lifestyles. Nathaniel Hawthorne uses the puritan’s strict lifestyles to relate to the universal issues amongRead MoreHawthorne s The Scarlet Letter872 Words   |  4 Pages Hawthorne’s novel, The Scarlet Letter, is a wonderful piece of writing that thoroughly analyzes the critiques and flaws of early Puritan society. Many enjoyable factors are present, including the heavy and enlightening use of symbols to develop Hawthorne’s revolutionary viewpoint as well as the strong portrayal of the characters that challenges ideas of the time. However, the book also has some flaws; most notable including the fact that the writing is an archaic writing style and thus is difficultRead MoreAntifeminist and Feminism within The Scarlet Letter1388 Words   |  6 PagesAntifeminist and Feminism within The Scarlet Letter In Nathaniel Hawthorne’s â€Å"The Scarlet Letter† Hester Prynne is accused and convicted of adultery. During the puritan era women in this society had specific obligations and rights they had to maintain. By Hester having an affair and acting unladylike the community disapproved of her actions causing everyone to isolate her in her town. Due to Hester Prynne’s Isolation and the harsh judgment she received from everyone in her town, she goes throughRead MoreWhat Is The Tone Of The Scarlet Letter By Hester Prynne928 Words   |  4 PagesD.H Lawrence a British writer critiques the novel’s Scarlet Letters heroine and gives his opinions on her in a persuasive, argumentative manner in his critical essay called On The Scarlet Letter. He believes that the heroine of the novel is not the beloved character readers believe she is. Using literary techniques like an ironclad tone, abrupt syntax and biblical allusions Lawrence convince’s people that the beloved American heroine Hester Prynne is truly a conniving adulteress who thrives off ofRead MoreEssay Nathaniel Hawthorne1152 Words   |  5 PagesNathaniel Hawthorne’s hatred of Puritanism was so big that he described in many of his writing such as The Scarlet Letter and The Minster Black Veil. He usually satirized them as evildoers and sin creators, not holy and Christ zealous as they described themselves. Hawthorne also used the effects of mysterious human mind and spontaneous action to describe the Puritan as satanic worship and God disobedience. In result, his writing reflected much of his Puritan ancestry affections. Nathaniel HawthorneRead MoreLiterature Has Functioned Throughout History As A Means1266 Words   |  6 PagesLiterature has functioned throughout history as a means of social criticism that is accessible to the lay public. Classics like Brave New World by Aldous Huxley and Uncle Tom’s Cabin by Harriet Beecher Stowe leverage their plots to reveal alarming realities and comment on social issues. The Scarlet Letter by Nathaniel Hawthorne is one of the earliest examples of literary social criticism. Hawthorne uses the plight of the main character, Hester Prynne, a convicted adulterer in a society that severelyRead MoreThe Inner Workings Of Hester Prynne1612 Words   |  7 PagesThe Inner Workings of Hester Prynne In Nathaniel Hawthorne’s novel, The Scarlet Letter, themes of sin and guilt are prominently displayed in the traits of the characters. The novel indicates the strong romantic presence of that time. It revolves around a young woman who is struggling to fit into a new town in a 17th century Puritan society. Hester Prynne, after moving to America to prepare a home for her husband Roger, makes a mostly independent life for herself in what is now Boston, MassachusettsRead More Characterization through Imagery and Metaphor in The Scarlet Letter1274 Words   |  6 PagesCharacterization through Imagery and Metaphor in The Scarlet Letter      Ã‚  Ã‚     Ã‚  Throughout his novel, The Scarlet Letter, Hawthorne reveals character through the use of imagery and metaphor.    In the first Chapter of The Scarlet Letter, The Prison-Door, the reader is immediately introduced to the people of Puritan Boston. Hawthorne begins to develop the character of the common people in order to build the mood of the story. The first sentence begins, A throng of bearded men, in sad-coloredRead MoreAre Women Destructive Forces?1674 Words   |  7 Pagesadversities in life had given her, but through the degree of her refusal to permit those adversities to direct her and decide who she ends up to be. Nathaniel Hawthorne wrote The Scarlet Letter in the early 1800’s about a disgraced woman who emerged from the shadows to alter the precise definition of the disgraceful letter â€Å"A† on her chest. Later, John Steinbeck composed Of Mice and Men in the 1930’s that depicted Curleys spouse as determined but also immensely egotistic, ultimately prompting hisRead MoreIs the Scarlet Letter a Proto Feminist Novel1510 Words   |  7 Pages21, 2012 Is The Scarlet Letter a Proto Feminist Novel? â€Å"Is The Scarlet Letter a Proto Feminist Novel?† The Scarlet Letter is a very well-known novel, between the scandals and lies. It starts off with a woman named Hester Prynne. Hester decides to leave her husband behind to migrate to Boston. A couple years later, Hester gives birth to a baby girl named Pearl in prison. Hester refused to reveal the father of Pearl. The town then forces Hester to wear a scarlet letter A upon her dress

Construction Law for Irn Construction PLC -myassignmenthelp.com

Question: Discuss about theConstruction Law for Irn Construction PLC. Answer: The JCT suit 2016 imposes an obligation of the both the employer and the contractor to comply with their legal duties. In the given scenario the contractor is Irn Construction PLC and the employer is U-turn investments. According to the facts of the given situation revised construction drawings have been provided by the architect of the employer and subsequently because of such actions the contractor was not able to proceed with the construction project. This is because the foundation of the project had been laid by the contractor in accordance to the original document. The new drawing requires a completely new foundation and along with other discrepancies the contractor are expected to delay the work by a total of 25 weeks. The limitations in relation to the progress of work are likely to trigger delay in the project and in addition would also result in the increase in the overall cost. It is a primary obligation of an employer under the JCT 2016 to provide the possession of the site to the contractor. In addition under the JCT 2016 the employer also has the duty to deploy appropriate administration in relation to the site along with providing necessary and relevant information and giving appropriate instructions. On the other hand the duty with the JCT 2016 imposes on the primary contractor include the responsibility of proceed with the work in accordance to the terms of the construction contract and also to deploy due skill and diligence with respect to the quality of work in the same way which a builder having ordinary competence would have done. In case any of the parties to the construction contract are not able to comply with the obligations imposed by the JCT 2016 it would lead to the breach of contract. The common law rules as provided by the case of Addis v Gramophone[1] would be applicable if the breach of contract has been done by any of the parties and t he aggrieved party would be entitled to remedies in form of compensation and damages. Damages are only provided to the aggrieved party for the loss arising out of contractual breach and to an extent which would restore the position of the party it would have been if the contract was not violated. It had been provided through the JCT 2016 that in case an act or omission committed on the part of the employer hampers the ability of the contractor to be able to complete the construction project on time, the contractor would be entitled to additional cost and time in relation the project from the employer. It is the duty of the contractor once they have been provided by the possession of the work site by the employers to appropriately initiate the construction project on time and to complete the project through continuously deploying skill and diligence[2]. In addition a duty has been imposed on the employer assist the contractor in completing the work and if it is found that the acts of the employer was committed in a manner which made in impossible or difficult for the contractor to continue with the progress of the work, than time being the essence of the contract cannot be relied upon by the employer in legal proceedings against the contractor. For instance where additional work or any contractual alternations have been initiated by the employer than it cannot be claimed by the employer that the contractor should complete the work in the originally provided time scale. According to the facts of the given situation where there has been alternation in the terms of the original contract by the employer it is the duty of the contractor to evaluate whether such alteration caused by the employer would be constituted as a significant situation leading to the not completion of work in time long with incurring additional cost. In addition the contractor also have the responsibility of analyzing whether such alterations by the employer is a fundamental change (alternation in the actual nature of the original contract which makes it a totally new contract) to the contract and thus make it impossible for the contractor to carry on with the work. In the given situation it has been provided that the contractor wants to carry on with the altered work with the expectations that the employer would be providing them the necessary benefits in relation to the additional cost incurred and delay cause to the project according to the provisions of the JCT. however for th e purpose of safeguarding its position it is the duty of the contractor to abide by the provisions of the contract. The clause 2.28 of the JCT provides extension of time to the contractor to deal with an alternation which may be considered as a relevant event[3]. In the given situation it is the duty of the contractor to provide a notice with respect to the time and variation issues so that they cannot be time barred. It is the duty of the contractor to provide a notice with respect to each delay to the employer. It is the duty of the contractor to provide notice in situation where not only the contractor has knowledge that the work would be delayed but when in situation where the wok is likely to be delayed as per clause 2.27.1 of the JCT[4]. The contractor has the duty to provide notice Forthwith which have been defined as without any delay in time[5] and as soon as it is reasonable to do[6]. The notice has to incorporate information about why it is considered by the contractor that a relevant event would be constituted by the discrepancies between contractual documents and the revised construction design. The likely impact of the event leading to the change in time and cost must also be a part of the notice. The material circumstances and the causes of delay must both be stated in the notice. Thing such as the proposed order of work, progress and any other thing which may affect the work must be considered as material circumstances. In case such notice is not provided by the contractor it can be argued by the employer that the contractor under the clause 2.28.6.1 did not utilize best judgment to prevent the delay[7]. It is the obligation of the contractor under clause 2.27.2 of the JCT according to which he has to provide details about the consequences of the every relevant event. It is the duty of the contractor to study every relevant event individually[8]. It is also the duty if the contract in case no other relevant event has taken place to inform the architects about the cost and time required completing the work after analyzing all the relevant events. Adequate data has to be supplied to the architect by the contractor so that they can come to a conclusion. The duty of the architect to develop an opinion in relation to the time extension does not initiate until and unless the notice as discussed above in relation to the estimation of the delay has been provided by the contractor according to the provisions of clause 2.28.1 of the JCT[9]. it is the duty of the architect to form an opinion in relation to two important matters, firstly, whether the causes notified by the contractor constitute a relevant event and secondly whether the relevant event is likely to delay the work beyond the prescribed deadline. A decision has to be made by the architecture in response to the claim of the contractor as soon as reasonably possible. Each relevant event caused by the employer has to be apportioned specific time by the architect. It is the duty of the architect to address and solve the problem based on the terms of the contract in an amicable manner. In addition, it is the duty of the architects of the employer to notify the contractors whether an extension have been provided or not according to the provisions of clause 2.28.2 of the JCT. the architect is prohibited from not informing the contractor if an extension has not been given to them after consideration[10]. The notification in relation to the non approval of the deadline extension has to be provided to the contractor by the architect in writing. It is upon the discretion of the architect to decide that whether the circumstances lead to a relevant event or not or whether such events would lead to a delay in work. An extension with respect to time has to be provided by the architecture under clause 2.28.3 of the JCT. while making an extension and fixing a new date of completion two things have to be stated by the architect firstly the amount of time which has been extended and secondly the deduction in time which arises out of every relevant omission[11]. The court who have the right to determine in the basis of both expressed and implied terms of the contract that how the matter should be proceeded if there is a failure on the part of the architect to do so. The court may not only make a specific action or an injunction order or an order to entitle the aggrieved party of damages incurred by them. It is the right of the contractor to complete the work in a reasonable time in case alterations have been made by the employer with respect to the original contract which makes it difficult for the contractor to complete the work[12]. The instruction of the architect in relation to discrepancies among the contractual documents as well as any default, prevention or impediments in form of an act or an omission on the part of the employer are included in the relevant events through which rights are conferred on the contractor to extend the time scale as provided by provision 2.29.2.1 of the JCT[13]. In case application has been made in writing by the contractor to the architects it is the duty of the architect to provide such information to the contractor within a reasonable period of time according to clause 2.12.2 of the JCT. the implied right in relation to the variation of work with respect to construction projects have been provided to neither the employer nor the contractor. Provi sions have been invariably provided by the JCT SBC/Q 2016 which gives the right to the employer to alter work subjected to the provided instructions along with making the contractor to carry on with the work or stop the work according to the instructions[14]. The nature of the terms of the contract would be used to determine whether the variation would result out of instructions provided by the employer. As per clause 3.10 of the JCT SBC/Q 2016 it is the duty of the contractor to act in accordance with all the directors provided to them by the architect and an order to make a variation can be provided by the architect under clause 3.14.1 of the JCT[15]. According to the case of McAlpine Humberoak Ltd. v. McDermott International Inc with respect to a construction contract variation by the employer cannot be made if it is related to a fundamental change in the contract and excluding large quantities of work and employer another contractor to carry on with such work. The situation would lead to the beach of the contract[16]. A detailed mechanism of valuation is set out by the JCT SBC/Q 2016 which enables employers to pay for varied works under clause 5.2. It is an amount which both the contractor and employer agree. The provisions for estimating the amount of time to be extended are provided in clauses 5.6-5.10 of the JCT. clauses 5.6 to 5.10 of the JCT provide the variation rules which make provisions among other things in circumstances where substitute or additional work can be measured. In case there is such a significant change in the parameter of the contract that its basic terms are no longer applicable it results in a fundamental change which is not in accordance to the primary intent of the contracting parties[17]. Such actions are indentified by laws as a violation of contractual terms and subsequently result in damages. The damages are based on the principles discussed above in the case of Addis v Gramphone, where the aggrieved parties initial position is intended to be restored as if it did not enter unto a contract. The dispute can also be solved through the use of Alternative Dispute Resolution Methods such as Negotiation, Arbitration, Conciliation and Mediation. Bibliography Adriaanse, Mr John.Construction contract law. Palgrave Macmillan, 2016. Aragona Constr. Co. v. United States, 165 Ct. Cl. 382 (1964) and C. Norman Peterson Co. v. Container Corp. of Am., 218 Cal. Rptr. 592 (Ct. App. 1985) Brook, Martin.Estimating and tendering for construction work. Taylor Francis, 2016. London Borough of Hillingdon v Cutler [1967] 2 All ER 361. London Borough of Hounslow v. Twickenham Garden Developments Ltd. (1970) 3 All E.R. 326 McAlpine Humberoak Ltd. v. McDermott International Inc. (No. 2) (1992) 58 B.L.R. 61 and Commissioner for Main Roads v. Reed Stuart Pty. Ltd. (1980) 12 B.L.R. 55. Roberts v Brett (1865) 11 HLC 337 Ter Haar, Roger, Marshall Levine, and Anna Laney.Construction insurance and UK construction contracts. CRC Press, 2016. Trollope Colls Ltd. v. North West Metropolitan Regional Hospital Board [1973] 2 All E.R. 260 and Peak Construction (Liverpool) Ltd. v. McKinney Foundations Ltd. (1970) 1 B.L.R. 111. Williams v. Fitzmaurice (1858) 3 H. N. 844

To Kill A Mockingbird Chapter Script Essay Example

To Kill A Mockingbird Chapter Script Paper Got in a fight with another man, he tried to cut me. Did he succeed? Yes such, a little, not enough to hurt, You see I-? ( Moves left shoulder Yes. You were both convicted? Yes such, had to serve cause couldnt pay the fine. Other fellow paid hisss. Leans across Scout to Gem. What is Tactics doing? Gem: showing the jury that Tom has nothing to hide. Were you acquainted with Male Violet Lowell? Yes such, had to pass her place going to and from the field every day. Whose field? Picks for Mr.. Link Ideas Were you picking cotton in November? No such, I works in his yard fall an wintertime. Arks pretty steady for Himalaya year round,hes got a lot of pecan tresss things. You say you had had to pass the Lowell place to get to and from work. Is there any other way to go? No such, nones I know of Tom, did she ever speak you? Why, yes such, Id tip m hat when Id go by, and one day she asked me to come inside the fence and bust up the chiffonier for her. When did she ask you chop up the-?the chif fonier? Mr.. Finch, it was way last spring. I remember it because it was Chopin time a and had my hoe with me.. I said didnt have nothing but this hoe, but she said she had a hatchet. She gave me the hatchet and broke up the chiffonier. She SAA reckon Ill haft give you a nickel, wont l? an I said, No, maam, there anti no charge. Then I went home. Mr.. Finch, that was way last spring, way over a 2 year ago. Did you ever go on the place again? Yes such. When? Well, I went lots of times. Judge Taylor reaches for gavel, but lets his hand fall as the murmuring in the audience die s down. Under me what circumstances? Please, such? Why did you go inside the fence lots of times? Toms forehead relaxes. Shed call me in such. Seemed like every time I passed by yonder shed have so title something for for me to do-?Chopin kindling, toting water for her. We will write a custom essay sample on To Kill A Mockingbird Chapter Script specifically for you for only $16.38 $13.9/page Order now We will write a custom essay sample on To Kill A Mockingbird Chapter Script specifically for you FOR ONLY $16.38 $13.9/page Hire Writer We will write a custom essay sample on To Kill A Mockingbird Chapter Script specifically for you FOR ONLY $16.38 $13.9/page Hire Writer She watered the red flowers every day-? Were you paid for your services? No such, not after she offered me a nickel the first time. I was glad to do it, Mr.. Lowell didnt seem to help her none, and neither did the chilling, and endowed she didnt have no nickels to spare. Where were the other children? They was always around, all over the place. Theyd watch me work, some of emend set in the window. 3 Would Miss Male talk to you? Yes sir, she talked to me. Did you ever At any time, go on the Lowell property-? did you ever set foot on he Lowell property without an express invitation from one of them? Tom: No such, Mr.. Finch, never did. I wouldnt do that, such. Tom, what happened to you on the evening of November Identifiers of last Spectators breathe collectively and lean forward. Negroes follow suit. Tom: Mr.. Finch, I was going home as usual that evening, an when I passed the Lowell place Miss Male were on the porch, like she said she were. It seemed real q tie like, an I didnt quite know why. I was studying why, just passing by, when she says for me to come there and help her a minute. Well, went inside the fence cooked around for some kindling to work on, but I didnt see none, and she say Ana, I got something for you to do in the house. The old doors off its hinges a n falls coming on pretty fast. said, you got a screwdriver, Miss Male? She said she shoo had. Well, went up the steps an she motioned me to come ins De, and I went in the front room an looked at the door. I said Miss Male, this d or look all right. Pulled it backs forth and those hinges was all right. Then she s heat the door in my face. Mr.. Finch, I was wondering why it was so quiet like, an it mom to me that there werent a Chile on the place, not a one of me, and I SAA d Miss Male, where the chilling? Begins to sweat, runs hand down face ) I say 4 where the chilling? An she says-?she was laughing, sort of-?she says they all gone to town to get ice creams. She says, took me a slap year to save sebum nickels, but I done it. They all gone to town What did you say then, Tom? Said something like, what Miss Male, thats right smart ahoy to treat me. An she said, You think so? I dont think she understood what was thinking-?l meant it was smart of her to sa ve like that. An nice of her to treat me. Understand you, Tom. Go on. Well, I said best be going, I couldnt do nothing for her, an she says Oh yes I could, an I ask her what, an she says to just step on that chair yonder an sit a box down from on top of the chiffonier. Not the same chiffonier you busted up? Witness smiles. Ana such, another one. Most as tall as the room. So I done what she told me, a n was just reaching when the next thing I knows, she-?shed grabbed me round t h legs, Mr. Finch. She scared me so bad I hopped down an turned the chair over-?that was the only thing, only furniture, stubbed in that room, Mr.. Finch when I left it. I swear fore God. What happened after you turned the chair over? What happened after that? Stops, glances at Tactics , then at the jury, and then across the room at Mr.. Underworld. Tom, youre sworn to tell the whole truth. Will you tell it? 5 Mr.. Finch, I got down Off that chair an turned around an she sorts jumped o Jumped on you? Violently? No such, she-?she hugged me. She hugged me round the waist. Strikes the gavel as the courtroom lights turn on. Tactics: Then what did she do? She reached up an kissed me side of the face. She says she never kissed a grog man before an she might as well kiss a Niger. She says what her papa do to h dont count. She says, Kiss me back, Niger. I say Miss Male lemma out there an tried to run but she got her back to the door an Id had to push he didnt want harm her, Mr.. Finch, an I say lemma pass, but just when say it Mr.. Lowell yonder hollered through the window. What did he say? Something not fitting to say-?not fitting for these folks chilling to hear-?. What did he say, Tom? You must tell the jury what he said. He says you goddamn where, Ill kill hay. Then what happened? Mr.. Finch, I was running so fast I didnt know what happened. To Kill A Mockingbird Chapter Script Essay Example To Kill A Mockingbird Chapter Script Paper Got in a fight with another man, he tried to cut me. Did he succeed? Yes such, a little, not enough to hurt, You see I-? ( Moves left shoulder Yes. You were both convicted? Yes such, had to serve cause couldnt pay the fine. Other fellow paid hisss. Leans across Scout to Gem. What is Tactics doing? Gem: showing the jury that Tom has nothing to hide. Were you acquainted with Male Violet Lowell? Yes such, had to pass her place going to and from the field every day. Whose field? Picks for Mr.. Link Ideas Were you picking cotton in November? No such, I works in his yard fall an wintertime. Arks pretty steady for Himalaya year round,hes got a lot of pecan tresss things. You say you had had to pass the Lowell place to get to and from work. Is there any other way to go? No such, nones I know of Tom, did she ever speak you? Why, yes such, Id tip m hat when Id go by, and one day she asked me to come inside the fence and bust up the chiffonier for her. When did she ask you chop up the-?the chif fonier? Mr.. Finch, it was way last spring. I remember it because it was Chopin time a and had my hoe with me.. I said didnt have nothing but this hoe, but she said she had a hatchet. She gave me the hatchet and broke up the chiffonier. She SAA reckon Ill haft give you a nickel, wont l? an I said, No, maam, there anti no charge. Then I went home. Mr.. Finch, that was way last spring, way over a 2 year ago. Did you ever go on the place again? Yes such. When? Well, I went lots of times. Judge Taylor reaches for gavel, but lets his hand fall as the murmuring in the audience die s down. Under me what circumstances? Please, such? Why did you go inside the fence lots of times? Toms forehead relaxes. Shed call me in such. Seemed like every time I passed by yonder shed have so title something for for me to do-?Chopin kindling, toting water for her. We will write a custom essay sample on To Kill A Mockingbird Chapter Script specifically for you for only $16.38 $13.9/page Order now We will write a custom essay sample on To Kill A Mockingbird Chapter Script specifically for you FOR ONLY $16.38 $13.9/page Hire Writer We will write a custom essay sample on To Kill A Mockingbird Chapter Script specifically for you FOR ONLY $16.38 $13.9/page Hire Writer She watered the red flowers every day-? Were you paid for your services? No such, not after she offered me a nickel the first time. I was glad to do it, Mr.. Lowell didnt seem to help her none, and neither did the chilling, and endowed she didnt have no nickels to spare. Where were the other children? They was always around, all over the place. Theyd watch me work, some of emend set in the window. 3 Would Miss Male talk to you? Yes sir, she talked to me. Did you ever At any time, go on the Lowell property-? did you ever set foot on he Lowell property without an express invitation from one of them? Tom: No such, Mr.. Finch, never did. I wouldnt do that, such. Tom, what happened to you on the evening of November Identifiers of last Spectators breathe collectively and lean forward. Negroes follow suit. Tom: Mr.. Finch, I was going home as usual that evening, an when I passed the Lowell place Miss Male were on the porch, like she said she were. It seemed real q tie like, an I didnt quite know why. I was studying why, just passing by, when she says for me to come there and help her a minute. Well, went inside the fence cooked around for some kindling to work on, but I didnt see none, and she say Ana, I got something for you to do in the house. The old doors off its hinges a n falls coming on pretty fast. said, you got a screwdriver, Miss Male? She said she shoo had. Well, went up the steps an she motioned me to come ins De, and I went in the front room an looked at the door. I said Miss Male, this d or look all right. Pulled it backs forth and those hinges was all right. Then she s heat the door in my face. Mr.. Finch, I was wondering why it was so quiet like, an it mom to me that there werent a Chile on the place, not a one of me, and I SAA d Miss Male, where the chilling? Begins to sweat, runs hand down face ) I say 4 where the chilling? An she says-?she was laughing, sort of-?she says they all gone to town to get ice creams. She says, took me a slap year to save sebum nickels, but I done it. They all gone to town What did you say then, Tom? Said something like, what Miss Male, thats right smart ahoy to treat me. An she said, You think so? I dont think she understood what was thinking-?l meant it was smart of her to sa ve like that. An nice of her to treat me. Understand you, Tom. Go on. Well, I said best be going, I couldnt do nothing for her, an she says Oh yes I could, an I ask her what, an she says to just step on that chair yonder an sit a box down from on top of the chiffonier. Not the same chiffonier you busted up? Witness smiles. Ana such, another one. Most as tall as the room. So I done what she told me, a n was just reaching when the next thing I knows, she-?shed grabbed me round t h legs, Mr. Finch. She scared me so bad I hopped down an turned the chair over-?that was the only thing, only furniture, stubbed in that room, Mr.. Finch when I left it. I swear fore God. What happened after you turned the chair over? What happened after that? Stops, glances at Tactics , then at the jury, and then across the room at Mr.. Underworld. Tom, youre sworn to tell the whole truth. Will you tell it? 5 Mr.. Finch, I got down Off that chair an turned around an she sorts jumped o Jumped on you? Violently? No such, she-?she hugged me. She hugged me round the waist. Strikes the gavel as the courtroom lights turn on. Tactics: Then what did she do? She reached up an kissed me side of the face. She says she never kissed a grog man before an she might as well kiss a Niger. She says what her papa do to h dont count. She says, Kiss me back, Niger. I say Miss Male lemma out there an tried to run but she got her back to the door an Id had to push he didnt want harm her, Mr.. Finch, an I say lemma pass, but just when say it Mr.. Lowell yonder hollered through the window. What did he say? Something not fitting to say-?not fitting for these folks chilling to hear-?. What did he say, Tom? You must tell the jury what he said. He says you goddamn where, Ill kill hay. Then what happened? Mr.. Finch, I was running so fast I didnt know what happened.